This case study aims at identifying operational challenges that are specific to multinational projects and the extent to which these projects contribute to fostering regional cooperation and integration. The study is based on the analysis of relevant documents and data mainly from the African Development Bank. It also draws on individual and focus group interviews carried out during a field work in Tanzania and Kenya between 3-15 July 2011. The Arusha-Namanga-Athi River Road Development Project was approved by the African Development Bank on 13 December 2006 for joint financing with the Japanese International Cooperation Agency (JICA). The overall project objective was to rehabilitate a major arterial trunk road with a regional bearing on trade and integration of the East African countries. The project has resulted in increased traffic flow, faster travel times, and lower vehicle operating costs. Development impacts such as increased cross-border trade, increased tourism and socio-economic development are still unfolding. Data on cross-border trade and other activities were not available, but interviews with stakeholders pointed to positive achievements. However, given the financing gap of about 45% in both countries to meet the cost of periodic maintenance of their road networks, sustainability of the road is at risk unless more pro-active measures are taken.
This case study assesses the extent to which the Arusha-Namanga-Athi River Road Development project, hereafter the project (see the bold yellow line of Appendix 1), contributes to fostering regional cooperation and integration, including whether the expected benefits have materialized, and whether they are sustainable and equitably shared. The study also assesses project efficiency and seeks to understand the factors leading to success or failure as well as the lessons that can be learnt.
The evaluation is mainly based on the African Development Bank (The Bank)’s documents and data. It also draws on the results of a mission undertaken in Tanzania and Kenya from 3 to 15 July 2011. The mission team carried out interviews and focus groups with several stakeholders, including senior officials, local governments, local communities and road users. Interviews and the focus groups were based on a checklist to help answer the evaluation questions (Appendix 4). Also, phone interviews with nine prominent business associations or firms exporting and importing to Tanzania or to Kenya were carried out based on a structured questionnaire (Appendix 2). The selection of stakeholders for the semi-structured interviews was based on the knowledge of interviewees of the road conditions over time. The selection of the nine business entities for phone interviews has been carried out by the regional consultant on the basis of the interest of the latter in using the road.
The selection of stakeholders for the semi-structured interviews was based on the knowledge of interviewees of the road conditions over time.
At the time of the mission, the project was still ongoing, though almost completed. Hence, long term development impacts were still to materialise. A quantitative assessment of the results achieved so far in terms cross- border activities could not be carried out because of lack of relevant information. Bank’s supervision mission reports available until July 2011 were used as main documentary evidence.
The transport sector has larger economic importance in Kenya than in Tanzania. At the time the project was initiated in 2006, roads in Tanzania carried about 80% of total passenger traffic and 75% of total freight traffic, through a network of 86,472 km, of which less than 8% was paved. Transport was estimated to account for 5.4% of GDP (United Republic of Tanzania 2008). In Kenya the transport network comprised about 195,000 km of roads, of which about 6% was paved. The sector represented 10.9% of GDP [
Regional transport policies aim at infrastructure development, accompanied by tariff reduction, elimination of non-tariff barriers and harmonization of procedures. Since 1998, the East African Community (EAC) has been highlighting the need to develop a modern regional road network, in order to improve regional trade and integration [
A Committee on East African Road Network Project was established and five road Corridors were identified as priority areas for action (Box 1). To facilitate trade along these Corridors, the EAC Treaty highlighted the necessity to eliminate non-tariffs barriers through harmonized standards, rules, procedures and practices [
EAC Partner States have implemented sector reforms aimed at a more efficient provision of services. These reforms include the formation of regulatory authorities and operational agencies, as well as privatization of operations [
Box 1. Identified corridors.
each one responsible for maintenance and development of a given typology of road, namely: Kenya Nation Highways Authority (KeNHA), Kenya Rural Road Authority (KeRRA) and Kenya Urban Roads Authority (KURA). Moreover, A Road Investment Plan (2008-18) was designed to implement full harmonization of the legislative framework governing roads in Kenya. The Kenya Road Board (KRB) was established in 1999 to manage financial resources for road maintenance.
Despite increased allocation of funds (from around Tshs.170 billion in 2001/2002 to over 1100 billion in 2010/2011), transport in Tanzania is still characterized by inadequate capacity, leading to low accessibility, especially to rural areas, and high transport costs, such as long journey times and poor urban mobility. Another major challenge has to do with collection of the fuel levy, affected by widespread tax evasion (39%, one of the worst collection rates in Sub-Saharan Africa), which hinders the securing of funds to operate and maintain roads. Similarly, although endowed with a larger network, Kenya public expenditure in transport is characterized by low rates of budget execution (60% in 2006) and a large rehabilitation backlog, i.e. a gap in the financing available to operate and maintain the road network. Rural accessibility is also problematic, as only 30% of Kenyan population lives within two kilometres from an accessible road [
The core objective of the project is to improve the transport conditions of the existing road connecting Arusha, Tanzania, with Nairobi, Kenya (see Appendix 1). The project consists of the rehabilitation and reconstruction of the 242 km road (136 km in Kenya and 106 km in Tanzania) and the construction of a One-Stop-Border Post (OSBP) in Namanga. The improved road is designed to have both larger carriageway (7 m width, surfaced with asphalt concrete) and shoulders (2 m width, surfaced with single bituminous). The One Stop Border Post is designed as the cordoning and fencing of an area of approximately 6.5 hectares to be designated as Border Control Zone (BCZ), within which access will be limited to persons, goods and services crossing the border (Box 2) [
The project is the result of a feasibility study started in 2003 and supported by the Bank with a grant of UA 0.94 million through its Technical Assistance Fund (TAF). The feasibility study demonstrated the project’s viability and readiness for implementation of the detailed engineering study [
In line with the development challenges identified in the preceding section, the project is expected to contribute to the establishment of major arterial trunk roads in order to facilitate cooperation and integration in East Africa. The road is of strategic importance as it is part of the priority Corridor N.5 of the EAC Regional Roads Network (Box 1 above), which spans from Tunduma in southern Tanzania to Moyale in northern Kenya, and onward to Addis Ababa.
Thanks to improved road conditions between Kenya and Tanzania, the project is expected to achieve positive development impacts. These include increased cross-border trade and tourism, increased socio-economic activities in the main towns of Arusha Namanga and Nairobi, and generation of new settlements along the road’s path. These goals should support the regional integration process between the economies of the two countries. The principal beneficiaries are expected to be national and regional transport operators, cross border traders, the tourism industry in both countries, and the residents in the project’s influence area [
Box 2. The one stop border post.
Source: JICA (2012).
In addition to the physical infrastructure, the project also comprises “soft” components, including two design studies for other cross-border roads between Kenya and Tanzania (Arusha-Holili/Taveta-Voi” and “Tanga-Horo Horo/Lunga Lunga-Mombasa-Malindi” roads), and two consulting services for capacity building. These latter concern the improvement of the technical capacity of the EAC with the recruitment and placement of two engineers into EAC’s ranks upon project completion and the preparation of a report recommending how to improve contracting capacity in East Africa.
Governance structure. The project’s governance involves a number of institutional actors at supranational, regional and national level. There are three executing agencies, one multinational Bank (AfDB) and one international donor (JICA). Two governments of sovereign countries and a regional development community, the EAC, are involved. TANROADS and KeNHA are the two governmental executing agencies responsible for road operations and development, respectively, for Tanzania and Kenya. The EAC is responsible for the implementation of the project’s “soft” components. In addition, monitoring during implementation is enforced through AfDB’s and JICA’s programmed supervision missions.
Institutional arrangements. Two committees have been set up to streamline and enhance coordination. At the policy level, a Steering Committee2 (SC) is in charge of policy issues and project governance. Its responsibility is to decide on strategic actions helping governments of the partner states to reach an informed common decision. The SC is a temporary body, which meets twice a year and comprises the Permanent Secretaries and Chief Executive Officers of the executing agencies from Kenya and Tanzania. Decisions of the SC are submitted to the Sectoral Council of Ministers responsible for Transport, Communications and Meteorology (TCM) and eventually to the Council, the executing organ of the Community. Any issue that remains unresolved in the SC, beyond an agreed timeframe, is enforced through Council directives. With this mechanism the SC makes its actors accountable. At operational level, a Technical Committee3 (TC) facilitates, coordinates and monitors all technical aspects of the project and advises the Steering Committee, when necessary. In the TC each country is represented by a Coordinator Engineer who is responsible for day-to-day implementation activities. The TC meets quarterly [
Project management. Although designed as one unique operation, the project consists of two standalone contracts running independently from one another during implementation. Civil works and consultancy services for the supervision of the works have been packaged in two separate lots: Lot T “Arusha-Namanga section” in Tanzania and Lot K “Athi River-Namanga section” in Kenya, following separate tendering processes (Box 3). On the one hand, a unique design guarantees unity and coherence of the engineering parameters. On the other hand, two separate construction contracts share the risks associated to the project (e.g. negative political developments).
The EAC played a positive “pivotal” role in project preparation and implementation. Before project approval, it facilitated the whole process of project’s preparation and in particular it contributed to mobilize funding from the Bank to support both design and preparation (grant) and implementation (loan). It thus played a key role in the upstream phase of the project cycle. During implementation, it is chairing both the Steering and the Technical Committees to keep overall project supervision and to ensure a smooth decision-making process. Although relatively complex, this governance structure contributes to keep all the actors under a common framework of mutual obligations and responsibilities and ensures coordination of activities.
Box 3. Tendering of civil works.
At appraisal, the cost of the project was estimated to be UA 98.516 million, of which 55.5% allocated to Kenya, 40.9% to Tanzania and 3.6% to the East African Community. ADF loans amounting to UA 49.24 million and UA 0.54 million were approved to finance the project components in Kenya and Tanzania, respectively. JICA approved UA 39.71 million for financing of the component in Tanzania. The remainder (UA 0.05 Million for Tanzania and UA 5.4 million for Kenya) was provided by national counterpart funding. Finally, an ADF grant of UA 3.5 million was approved to the EAC to implement the project’s soft components.
The project responds to the needs of both Kenya and Tanzania to improve road transport infrastructure and to increase and deepen the links between their economies. The project is aligned with the EAC’s Regional Development Strategy of support for the development of transport corridors. Civil servants from local governments and representatives of local communities have also identified inadequate infrastructure (especially transport and energy) as bottlenecks to regional development (Box 4). Stakeholders from the private sector reflected the same opinion, identifying poor infrastructure as one of the main challenges to growth and development, together with regulatory issues (customs, common standards), political instability and security, and poor skills.
However, although transport is still considered a top priority, private operators interviewed in Tanzania have identified energy as the leading bottleneck, immediately followed by roads, ports and railway. More specifically, given the current severe power shortages in the country, regional development initiatives could have facilitated grid connection between Tanzania, southern Africa and Uganda. In this way, surplus energy could have been exported to Tanzania rather than Tanzania reverting to emergency power supply which is unnecessarily expensive. On the Kenyan side, energy is ranked second, with roads and railways considered the first priority.
From the analysis of the project concept and logical framework, the relevance of the “soft” components and how they are aligned with the project’s core objective is not explicit for all the components. The two study designs are synergic with the Arusha Namaga-Athi River road since they concern roads belonging to the same network of arterial trunk roads between Kenya and Tanzania holding a regional bearing. For instance, the Arusha-Holili/Taveta-Voi road is important for the import and export of Northern Tanzania since it connects the region of Arusha with the Mombasa port. On the face of it, the objective of the capacity building components is loosely connected to the achievement of the project’s core objective. Indeed, the preparation of a report about the capacity of local contractors in East Africa has little to do with the increase of cross-border trade and tourism.
The project is also consistent with the Bank’s central goal of supporting the transport sector in both countries. This is reflected by relative volumes of ADF approvals in their portfolios of operations (Box 5) [
Component | Tanzania | Kenya | EAC | Total | |||
---|---|---|---|---|---|---|---|
Source | Amount (UA million) | Source | Amount (UA million) | Source | Amount (UA million) | Amount (UA million) | |
Physical realisation | ADF GoT JICA | 0.537 0.054 39.712 | ADF GoK | 49.241 5.472 | |||
Soft components | ADF | 3.500 | |||||
Total | 40.303 | 54.173 | 3.500 | 98.516 |
Source: African Development Fund (2006). Arusha-Namanga-Athi River Development Project, Appraisal Report.
Box 4. EAC interviewee.
Box 5. The Bank’s assistance strategies in Tanzania and Kenya.
Quality-at-Entry (QAE) was unsatisfactory. The project was designed as a multinational operation and some effort was made to harmonize the technical standards including carriageway width, pavements, surfacing, weigh- bridges, etc. This harmonization effort required preliminary dialogue and agreements at policy level, which took place within the coordination framework of the EAC. However, there were a number of deficiencies that had implications for the timing to attain the expected effects.
Forecasts in the appraisal report underestimated the actual costs as shown by subsequent estimates of the detailed engineering study [
The Economic Rate of Return (ERR) and the Economic Net Present Value (ENPV) were estimated at, respectively, 17.1% and USD 26.42 million, by applying a social discount rate of 12% (
The implementation schedule was tight. In order to maintain the project’s positive economic viability, the Appraisal Report states that “it is imperative that the whole project should be implemented immediately without delay”. Accordingly, a tight implementation schedule was set up: five months from the Board’s approval to the works contract signature and three years to complete construction. However, delays occurred before the project’s took-off as well as during implementation, leading to low utilization ratios of the Bank’s funds. Again, these delays have negative effects on the economic viability of the project, since they postpone in time the occurrence of benefits (and thus make the ENPV decrease).
The project preparation in Tanzania lacked a technical project review. In practice, owing to inadequate cost provisions at appraisal, works started without a review of the detailed engineering study. As consequence, some technical problems occurred during implementation. For instance, there was a bridge with inadequate size for the new road when the project started. Corrective measures to address this situation further delayed the project’s implementation.
Information gathered from the interviews with stakeholders of both the public and the private sectors suggest that their involvement in design and implementation modalities was limited. The representatives from local governments and local communities affected by construction works declared to be involved only in the course of implementation, and only in cases of properties or environmental damage. Also, the private sector was not involved. None of the interviewed business associations and firms in Kenya and Tanzania was ever consulted in any of the project cycle stages. Even the East African Business Council (EABC), the regional private sector body, was not consulted by the project promoters. However, designing the rehabilitation of an already existing non-tolled road requires taking decisions which are of technical nature, rather than political, as it happens for example with new investments, where strategic decisions about location/route of the infrastructure, tariff policy, resettlements, etc. need to be taken. As a consequence, wider consultation of stakeholders would have had an
Road Section | ENPV (USD million) | ERR (%) |
---|---|---|
Arusha-Namanga | 13.89 | 19.5 |
Namanga-Athi River | 12.53 | 15.7 |
Overall project | 26.42 | 17.1 |
Source: JIBB consultancy services, Addendum to Final Economic Report, September 2006.
impact in terms of larger awareness, but it is unlikely that the design would have been modified. Probably, the only technical parameter that could have changed is where to locate parking stations.
The most important weakness is that design for the implementation of the One Stop Border Post was not completed at the time of project preparation. The original feasibility study of 2003 designed the road without any provision to build a border post at Namanga because, at that time, the concept of One Stop Border Post was not yet on the political agenda. This came later on and the decision to add the One Stop Border Post was taken when the Bank mounted the appraisal mission in 2006. The intention was to finalize its design into the course of road implementation through a subsequent grant financing. Since no funds were available at the time of preparing the bidding documents in both Tanzania and Kenya, it was agreed that construction contracts would have made allowance for lump sums. These would have partly financed the OSBP, pending finalization of the detailed design study. However, this situation created an impasse resulting in overall implementation delays. In fact, the design of the One Stop Border Post was completed only in November 2010, with funding from JICA, when works on the road were already at an advanced stage. The further necessity to dialogue and agree on how to harmonize national-based standards and to introduce common computerized procedures to operate the custom added complexity and delays. This is the key bottleneck of the project, which delays the attainment of the expected benefits.
Currently, land acquisition, resettlement and compensation of the Project Affected People (PAP) have been completed on both the Kenyan and Tanzanian sides. The costs amount to USD 8.91 million and USD 2.68 million on the Kenyan and Tanzania sides, respectively. The high cost of compensation and resettlement is attributed to the significant development of private businesses on the Kenya side of the border. Specification of the harmonization of custom procedures to operate the facility is ongoing through bilateral agreements between governments, within the overall coordination of the EAC as facilitator of the dialogue. The construction of the One Stop Border Post facilities on both sides will be considered as addenda to the existing contracts [
The attainment of objectives is satisfactory. The project generates a number of direct and indirect economic effects as shown in
Since it is still ongoing, not all the project’s outputs have been realised. Concerning physical realisations, as of the date of the mission (July 2011), 99.84 km out of 104.20 km were surfaced and were open to traffic in Tanzania. In Kenya, 132 km of the 136 km were surfaced and were open to traffic. The One Stop Border Post was not yet in place.
As far as “soft” components are concerned, the two design studies have been completed. However, owing to cost underestimation of these studies, their costs were partly covered by transferring funds originally allocated for capacity building. This left inadequate resources for the capacity building components, including the recruitment of two engineers. These engineers were supposed to co-ordinate the execution of all project’s components handled by the EAC, i.e. to coordinate the implementation of the road design studies as well as the study on contractors’ capacity in EAC region. They were also supposed to continue working as EAC’s staff after project completion. According to interviews, however, the non-realization of the capacity building components, and the missed recruitment of the engineers, has not affected the achievement of the project’s core objective. The only, limited, impact was that coordination activities reverted to other engineers, already employed in EAC, who had additional work to perform. This suggests that the objectives of these components were not vital to the project’s development.
Results Chain Level | Effect | Indicator | Baseline (2004) | Target (2011) | Actual (2011) | Judgement |
---|---|---|---|---|---|---|
Outputs | To rehabilitate the road between Arusha and Athi River | Km of road | 0 | 242 | 232 | Positive |
To reduce cost of cross-border transactions | N. of OSBP | 0 | 1 | 0 | Negative | |
To study the feasibility of other cross-border roads | N. of cross-border road design studies | 0 | 2 | 2 | Positive | |
To improve the technical capacity of the EAC | N. of new engineers in EAC’s rank | 0 | 2 | 0 | Very negative | |
To improve knowledge on contracting capacity in East Africa | N. of reports | 0 | 1 | 0 | Very negative | |
Outcomes | To increase traffic between Arusha and Athi River | Annual Average Daily Traffic (AADT) | - | +36% | +45%* | Positive |
To reduce travel time | Travel time (minutes) | 240 | 150 | 150 | Very Positive | |
To reduce cost of trip | Vehicles operating cost (USD per vehicle/km) | 0.56 | 0.45 | 0.42 | Very Positive | |
To increase road safety | N. of accidents | - | - | - | Uncertain | |
Development Impacts | To increase cross-border trade | Freight crossing the border at Namanga (tonnes/years) | 104,000 | 131,000 | - | Positive** |
To enhance tourism | N, of tourists crossing the borders | - | - | - | Positive** | |
To boost socio economic development | N, of new businesses along the road | - | - | - | Positive** |
Note: Empty cells means data are not available. *Data referred to Kenya section only. **Qualitative assessment. Source: From TANROADS and KENhA data.
While there is no data available for Tanzania,
Travel time savings: Improved road conditions have the direct effect of reducing travel time for road users (
According to minibus drivers and a representative of the Kenya Long Distance Truck Drivers Association, the costs that depend directly on using the vehicles (tire changing, car repairs, etc.) decreased thanks to improved road conditions. Rough estimates provided by interviewed respondents indicate a decrease of vehicle operating costs of about 20% - 30%. According to baseline data provided in the appraisal report, this would mean a decrease of vehicle operating cost from USD 0.56 vehicle/km to USD 0.42 vehicle/km. Vehicle operating costs considered here do not include fuel consumption since this is mainly related to traffic congestion and not to road conditions.
The net effect on road safety is controversial and still to be verified. On the one hand, wider carriageway and shoulders, together with better visibility, are safer than a narrow road. On the other hand, better road conditions encourage users to drive at higher speed. In these conditions, low education concerning road safety can lead to
Year | Total | Motor cycles | Cars | Pickups, Jeeps, 4WDs, Vans | Minibus | Buses | Light Trucks | Medium Trucks | Drawbar Trucks | Agricultural Tractors, Graders, etc. |
---|---|---|---|---|---|---|---|---|---|---|
2004 | 6196 | 27 | 2373 | 1442 | 1616 | 168 | 110 | 317 | 138 | 5 |
2010 | 8957 | 77 | 2913 | 1866 | 1507 | 259 | 508 | 426 | 692 | 10 |
Increase (%) | 45 | 185 | 23 | 29 | −7 | 54 | 362 | 34 | 401 | 100 |
Source: GIBB, Kajiado observation, Kenya.
Section | Before (minutes) | After (minutes) |
---|---|---|
Arusha-Namanga | 100 | 60 |
Namanga-Athi River | 140 | 90 |
Source: interviews.
an increased number of accidents, especially in the areas populated with animals crossing the road and in urban centres. One of the interviewees has argued that “with the road in worse conditions, there were fewer accidents, because vehicles could not over speed”. This risk was already foreseen in the Environmental and Social Impact Assessment (ESIA), which envisaged a series of mitigation measures including improved parking bays, provision of services roads on busy areas, provision of pedestrian crossing on bridges and high gorges, widening of the road in some places to allow for bicycle paths and pedestrian sidewalks. As of the mission’s date, these facilities were not built, but later information gathered from the Bank’s project managers indicate that they have been constructed since then. However, any reliable assessment about the actual project’s effect on accidents would require a track of statistical information, which is not yet available.
The project’s core development impact is the facilitation and increase of cross-border trade [
Socio-economic development: housing dynamics, new settlements and land valorisation are unfolding. Increased business opportunities are attracting population to the districts along the road. New settlements have emerged notably in Longido, Tanzania, due to increasing internal and cross border trading activities and because people from Arusha are investing in housing while continuing to work in Arusha. This is also the situation in agglomerations next to Nairobi, such as Kitengela. In general, small business clusters are being set up along different parts of the road. Land and real estate prices have drastically increased in some agglomerations along the road and secondary and tertiary activities such as cement, steel, and animal feed plants, and universities are being set up. Although all these effects cannot be attributed to the project alone, it is likely that in the absence of the project, fewer business opportunities would have emerged, the movement of population would have been constrained, and competitiveness reduced owing to higher transport costs [
The road would benefit the tourism economy at regional level because it improves accessibility to major tourist attractions including Mt. Kilimanjaro, Arusha National Park, Amboseli National Park and Chyulu Game Reserve. According to 2005 estimates, i.e. before project’s implementation, 24% of all tourists’ arrivals in Tanzania entered through Namanga, having travelled on the project road. With the road in good conditions, this data is expected to grow significantly. In particular, the road offers to tourists a reliable transport mode alternative to air in order to access the major tourist attractions of the area [
The road passes through an area of very low population density, supporting Maasai pastoralist groups. As identified in the Environmental and Social Impact Assessment, the project should generate limited negative impacts on environment, mainly related to damages during construction. However, evidence collected at Mavoko (Kenya) city council suggests that damages occurred in the agglomeration of Kitengela have been of an exceptional magnitude. These consisted of village and feeder roads destruction due to the passage of heavy vehicles and trucks, which had to use these roads as by-pass during construction. This issue was not foreseen upfront by the ESIA and, consequently, no mitigation measures were identified [
Both countries will benefit from improved road infrastructure conditions, as traffic will be more fluent on both directions and trade facilitated on a regional basis. As far as gains from trade are concerned, reduced transport costs usually enhance export opportunities, strengthen competition and widen productive factor markets [
Respondents from private sector also believe that the project has greater impact on tourism industry in Kenya than in Tanzania. First, this is because the priority in Tanzania rests on linkages between northern and southern national tourist circuits. Second, road facility linking efficiently Nairobi and Arusha may have even potentially negative effects on tour operators’ business in Tanzania. One respondent, for example, indicated that “we actually prefer the road to be in bad shape so that tourists land in Kilimanjaro International Airport, instead of landing in Kenya and then drive to Arusha”. Vice-versa, tour operators in Kenya may exploit the road in good condition and increase their business by organizing trips to Arusha region from Nairobi.
As far as distribution of benefits among stakeholders is concerned, the project generally brings positive effects. All road users, such as truck drivers, cross-border traders, transport operators (e.g. minibus, matatu, etc.)
Box 6. Trade developments between Kenya and Tanzania.
Source: www.eac.int and United Republic of Tanzania (2013).
and private cars benefit from road’s rehabilitation [
Overall, the project implementation is efficient, although with some delays and cost overruns resulting from some predictable and unpredictable adverse events. Since project implementation is being carried out through single independent contracts, the detailed analysis of the implementation performance is also structured separately for the two countries (
Procurement process was delayed as compared to the initial time schedule. The main cause of delay before project commencement was related to the procurement process. About one and a half year was spent on procurement, against the six months planned. Civil works contract was signed on June 2008 against planned June 2007. This was due to diverging interpretations between the Bank and TANROADS on some technical aspects of the bidding. This has led to extended time to obtain the Bank’s non-objection. However, to partially mitigate this negative performance, it must be recalled how the implementation schedule imposed a tight deadline on the execution of all tendering activities and fulfilment of the conditionalities of the Bank [
Expected cost at completion is in line with forecasts, although the project progress is behind the planned schedule. In July 2011, the reported slippage was of 156 calendar days. According to the latest data available, overall progress of civil works stands at 78.52% against the originally planned 93.61%. The contract time elapsed to-date was 1082 calendar days or 98.81%. Given the expected works completion dated 13 July 2011, the Contractor (China Geo Engineering Corporation) requested and certified an extension of time of 156 calendar days, with new expected date of completion set in December 2011. Including the construction of the OSBP, the work completion date is expected by January 2013.
The analysis of major causes of delay shows that these are technical in some cases and institutional in others. The most important cause of delay was the flooding, which could not be foreseen. Other causes, on the contrary, could have been avoided if adequately addressed during the project design and preparation stage. For instance, another daunting, but predictable, implementation constraint was the delayed GoT counterpart payments which has pre-empted the contractor to timely execute the work.
Overall, despite the potential right to stop the works, the contractor could keep fairly good working relationships with the supervision contactor (J. Burrow) and the executing agency (TANROADS). This behaviour was a key determinant allowing to overcome project implementation challenges. Other positive factors included the presence of a regional manager from TANROADS in the field, who acted as constant reference point for the contractor and the supervision consultant so as to speed up the decision-making process.
The procurement process has been managed smoothly and timely. ADF loan has been approved in February 2007, the tender launched in March and the selection of candidate in September 2007. On 3rd October 2007, the civil works contract was signed for a 36 months period, representing 3-months delay against the planned schedule.
Implementation progress is behind the planned schedule and costs have been overrun. In July 2011, overall progress stood at 89%, against the originally planned 100%, 132 km of the 136 km had been surfaced and was open to traffic. The Contractor has obtained two extension of time for a total of 214 calendar days. Expected cost at completion is estimated at 116% (allowing the whole contingency sum to be consumed). Including the construction of the OSBP, the expected date of completion is August 2013.
The analysis of the major causes of delay and cost overruns shows that they range from political to procedural and financial reasons. The most daunting problems were due to uncontrollable circumstances such as the political situation prevailing after the disputed presidential election of 27 December 2007 in Kenya, and the strikes of the workforce. Also, the most important predictable factor hindering implementation performance was
Problem | Nature | Predictability in the design phase | Proposed corrective measure |
---|---|---|---|
Flood overtopping During February 2011, the road was overtopped by flood waters at five locations causing significant damages to the works. | Technical | NO. The design consultants have been approached and have inspected the locations coming to the conclusion that the capacities of the designed drainage structures were adequate. Considered that the area where the project takes place is a semi-arid land, the likelihood of occurrence of such an event is about one each ten years. A different project design, explicitly envisaging this event, would have not been consistent with standard specifications. | It was agreed that the supervision consultant mobilizes a hydrologist to immediately review the capacities of the structures at the said locations and recommend corrective measures and cost implications. The report of the hydrologist should be shared with the Bank. The Contractor should be instructed without any further delay for the additional crossings where there is capacity inadequacy. |
Paving surface defects On October 2010, asphalt surface defects, in terms of regularity of the thickness, have been noted between km32+000-41+000; km50+000-54+000; and km89+000-94+000. | Technical | NO. The design of the paving surface has been assessed as adequate. The defects are due to a Contractor’s error. | It is agreed that the Contractor rectifies the defects at its own cost. |
Bridge width The kerb to kerb width of the bridge at km72+000 is 29.4 m far below 36.6 m, the width required to cover the carriageway and the usable shoulders. | Technical | YES. The bridge was already existing and provisions on how to widen it should have been included in the project design. | The Executing Agency, in agreement with the advised of the AfDB task manager, accepts to widening the bridge to provide walkways on either side for pedestrians. The Contractor and the Consultant agree on the equipment to purchase. |
Delays on GOT counterpart financing GOT has only partially met its obligations. GOT portions of the invoices n. 7 - 13 are still not paid, for a total amount of TZS. 239.3 million and USD 1.05 million. As a result the Contractor gave a notice to reduce the rate of work in accordance with the contract conditions. | Institutional | YES. In the initial financing agreement GOT financing was limited to only part of the supervision consultancy contract, and not the civil works, for a total counterpart funding equal to UA 0.054 million (about 0.13% of the combined cost of civil works and consultancy services). However, since ADF and JICA loans have been issued before the execution of more accurate cost estimates and the contract price was higher than the amounts agreed, GOT had to cover the cost over and above the available financing from JICA and ADF, as well as taxes. GOT counterpart, including taxes, accounts today to UA 5.8 million. Given the difficulties the national treasury is encountering to face its various commitments to roads development and maintenance, more accurate cost estimates at appraisal stage would have prevented the necessity to mobilize national funds. | The Contractor forwarded repeated notice on the delay of the IPCs seeking for immediate payment. He also notified that his progress was affected due to this cash flow shortage. The Employer has been asked to take the necessary action before the Contractor takes serious measures. Apart from that, no particular action has been undertaken at political or institutional level, e.g. by the EAC, to induce GOT to fulfill its requirements. |
Absence of experienced skilled manpower The Contractor is facing difficulties to recruit foremen, masons and excavators to engage on landscaping works. | Technical | YES. Given the in-depth knowledge of TANROADS about the socio-economic context of Arusha region, including the local labour market, a more accurate plan for recruitment of local labour force could have been elaborated and included in the contract so as to bind the Contractor to some specifics guidelines. | The Consultant is pushing the Contractor to mobilize additional excavators, employ sufficient and experienced manpower (foremen and masons) and/or sublet to the specialized sub-contractors to expedite the lined drain work. |
Source: Authors elaboration.
Problems | Nature | Predictability in the designing phase | Proposed corrective measure |
---|---|---|---|
Delayed payments from ADF As of December 2010, invoices n. 17 and 18 were paid very late and n.19 is yet to be paid by the Bank, yet GOK has paid its part. | Procedural | YES. The procedure to pay a certified invoice can take up to 6 months. Although independent from the project implementing bodies, this event is assessed as predictable since it concerns well-established procedures existing between GOK and AfDB. | The contractor has stopped the works or reduced the rate of activity in several occasions until the payments were processed. To respect the implementation schedule, financial resources have been borrowed from China Bank. AfDB task manager promised that the Bank will do the necessary so that payments will no longer be delayed. |
Adverse climatic condition | Technical | NO. The level of rainfalls occurred between September 2009 and April 2010 was of an exceptional nature. | N/A |
Variation of prices The trend for variation of prices indicates a projected completion amount 326% above the contingency allowed for in the contract. | Financial | YES. A study of the current inflating trends of goods and services could have provided more accurate estimates about the magnitude of the financial contingency. | The Bank’s supervision mission advised that the indices for the Variation of Prices need to be reviewed on the basis of the actual indices, as some of them look to be on the higher side. |
Post-election violence After the disputed presidential election of 27 December 2007 the port of Mombasa has been closed due to violence and demonstrations. | Political | NO. The fact could not be predicted. | N/A |
Illegal strikes of the recruited local manpower | Political | NO. The fact could not be predicted. | N/A |
Source: Authors elaboration.
the delayed payments from the ADF due to lengthy Bank’s procedures to pay certified invoices. One factor which led to overcome project implementation challenges was that the contractor, who got his first assignment in Kenya, was committed to make special efforts to achieve the desired results in order to establish a good reputation, a “Fare bella figura” according to Hirschman (1967) [
To sum up, given the magnitude of the cost overrun and delays, which are within a reasonable order, and considering that several implementation obstacles were external and not predictable by the project management, the project is assessed to be efficiently implemented. The implementation is slightly more efficient in Kenya than in Tanzania, where it suffered from a late take-off (
Sustainability is at risk due to weak capacity for roads maintenance. As of the mission date, both countries were experiencing a financing gap of about 45 percent of financial resources needed to meet the cost of periodic maintenance of their road networks (Box 7). The current maintenance policy of trunk and regional roads is to prioritize the preservation of all roads that are already in good condition by channelling funds to cover their full routine (day-to-day) and periodic (each 7 - 8 years) maintenance. This policy is generally referred to as “to maintain the maintainable first”. The basis for this policy is that in the past, neglecting to repair simple road failures over time, led to full scale deterioration of the roads, which eventually required capital investment for rehabilitation and reconstruction, as in the case of the Arusha-Namanga-Athi River road [
Expected | Actual | |
---|---|---|
Duration of procurement | Tanzania: 5 months | Tanzania: 18 months |
Kenya: 5 months | Kenya: 8 months | |
Duration of civil works* | Tanzania: 36 months | Tanzania: 42 months |
Kenya: 36 months | Kenya: 46 months | |
Cost | Tanzania: UA 40.3 million | Tanzania: N/A |
Kenya: UA 54.7 million | Kenya: UA 61.8 million |
*Excluding the OSBP. Source: AfDB supervision mission summaries.
Source: http://www.krb.go.ke; http://www.roadsfundtz.org/web/index.asp
Since it has just been rehabilitated, the Arusha-Namanga-Athi River road is likely to be prioritized by Governments so as to obtain routine maintenance immediately after defect liability period expires, and periodic maintenance, which will become due until 7 - 8 years after construction (around 2020). However, both countries face a problem of limited resources in the face of road maintenance needs and the possible political preference of new investments to maintenance. If not adequately maintained, the road will fall in the group of “poor roads” for which maintenance is not assured.
The Arusha Namanga-Athi River Road Development Project is a project of regional importance which is a part of the African highway from Cairo in Egypt to Cape Town in South Africa. It is already producing expected results in terms of increased traffic, travel time savings, vehicle operating costs reduction. It is likely to produce increased cross-border movement of people and exchange of goods and services between countries. The road is also fostering development of economic activities. New settlements and small business clusters have emerged along different parts of the road and touristic activities increased. There has been an increased secondary and tertiary activities and high population growth in some agglomerations notably next to Arusha and Nairobi.
Weak design aspects including late design of the OSBP, cost underestimation, lengthy Bank’s procedures and delayed counterparts funding, have produced time and cost-overruns during implementation. However, since several implementation obstacles were not predictable by the project management (e.g. the political situation prevailing in Kenya after elections of December 2007 and the flooding in Tanzania), the project could be considered to be efficiently implemented.
Factors that allowed overcoming obstacles included:
・ The advisory services of the Bank’s Field Offices experts;
・ The contractor’s commitment to high performance, with a view of establishing a good reputation in the region;
・ The good working relationships kept between contractors, consultants and executing agencies;
・ The constant presence of representatives from the executing agencies.
Capacity building components have not been realised. However, this was not a serious obstacle to the realisation of the core objective of the project to reduce transport cost in order to facilitate cross-border activities between Kenya and Tanzania. This reflects a loose connection between the capacity building components and the project’s overall rationale. The governance structure of the project has contributed positively to the project development, both during the project design and implementation phases. The EAC played a pivotal role as a regional coordinator and supervisor.
Lack of inclusion of provisions for the One Stop Border Post within the original project design proved to be a major constraint delaying the expected regional integration effects of the road. The implementation of the One Stop Border Post requires setting up a physical realisation but also to engage into policy dialogue and conclude bilateral agreements between governments to overcome non-physical barriers. This is to enable the harmonisation of national-based rules and standards as well as make possible the introduction of common computerized custom procedures to operate the facility.
The structural financing gap of about 45 percent for road maintenance and the risk of competing demands for maintenance as well as the potential political preference given to new investments are indications that a potential risk on long term sustainability exists.
table 9 presents the overall scores for each evaluation criteria.
Criterion | Scores | Assessment |
---|---|---|
Relevance | 4 | Fully relevant |
Quality-at-entry | 2 | Unsatisfactory |
Effectiveness | 3 | Satisfactory |
Efficiency | 3 | Satisfactory |
Sustainability | 2 | At risk |
Overall Performance | 3 | Satisfactory |
Highly satisfactory: 4; satisfactory: 3; unsatisfactory: 2; very unsatisfactory: 1.
Alignment of development priorities of the participating countries and adequate governance arrangements are necessary conditions to ensure successful implementation of a multinational operation.
The capacity building components of a project must be consistent with the main project’s rationale to be effectively implemented; otherwise they risk to be neglected.
Inadequate financial provisions for One Stop Border Post hamper the timely achievement of regional integration objectives of multinational roads.
Unless appropriate financing mechanisms for maintenance of road projects are put in place, the sustainability of reconstructed/rehabilitated roads remains at risk.
Lack of adequate monitoring and evaluation prevents a timely evaluation of the outcomes and impacts of the roads. This is a recurrent lesson.
Albert-EnéasGakusi,DavideSartori,EmmanuelMaliti, (2015) Fostering Regional Integration in Africa: The Case of Arusha-Namanga-Athi River Road Development Project*. Open Journal of Social Sciences,03,212-235. doi: 10.4236/jss.2015.312025
A. Questionnaire
Name of the Company:
Respondent title and name:
Date of interview:
Participatory approach
1) Have you been engaged/consulted by AfDB prior to the initiation of the project?
a) What level of consultation took place: individual meetings, seminars with your sectorial association, direct consultations with AfDB, etc.?
b) Does the consultation take place at different stage: identification, design, implementation, post-comple- tion?
Relevance
2) Provide ranking on the following [1st, 2nd, 3rd] based on how your members perception regarding the leading challenge to private sector development in the region
a) Infrastructural bottlenecks.
b) Policy (customs, monetary, sectoral).
c) Political.
3) Compared with other “infrastructural” needs, was this project a top priority for your business operations
a) What other “infrastructural needs” you considered to be of top priority for your company?
b) What were the main challenges faced by the business community prior to the project?
4. How do you rate political commitment of the regional member countries on accelerating economic integration in the region under the EAC framework?
a) In terms of sustaining the results of infrastructural regional projects?
b) In terms of other non-infrastructural areas? (Policy reforms and project implementation).
Effectiveness
5) What specific economic and social benefits have materialized because of this project? (or expectation given your business experience):
a) Tourism industry (for tour companies).
- Transport costs (vehicle operating costs).
- Improved road services (travel time).
- Enhanced tourism in Arusha region and Tsavo in Kenya.
b) Cross border trading (manufacturing-export companies).
- Transport costs (vehicle operating costs).
- Improved road services (road roughness; travel time).
- Increased volume of motorized traffic/business volume.
c) Population (Kajiado and Nairobi districts).
- Transport costs (vehicle operating costs).
- Improved road services (travel time).
- Increased businesses activities along the road.
6) What factors do you perceive to be cause of success/failure of regional projects?
a) What do you think are the necessary conditions for the sustainability and for the regional operations to achieve their full benefits?
b) Do you think these factors are “considered/taken into account” by donors and/or member governments when undertaken regional initiatives?
B. Results
Based on the discussions with stakeholders, the following ratings4 were generated from each interviewee. The main criteria are three, each with three sub-criteria. The table below presents an overall assessment followed by individual assessment from each of the 8 firms.
Summary of the assessment
Firm 1
Firm 2
Firm 3
Firm 4
Firm 5
Firm 6
Firm 7
Firm 8
Source: AfDB data bases.